KW405-220207/A - Transformer End of Life Replacement at Canadian Center for Inland Waters (CCIW) (KW405-220207/A)

Trade Agreement: Canadian Free Trade Agreement (CFTA) Tendering Procedures: All interested suppliers may submit a bid Competitive Procurement Strategy: Best Overall

Proposal Comprehensive Land Claim Agreement: No Nature of Requirements:

Transformer End of Life Replacement at Canadian Center for Inland Waters (CCIW)

KW405-220207/A Kwan, Isaac Telephone No. - (343) 573-3068 (

) Fax No. - (416) 952-1257 (

)

NOTICE OF PROPOSED PROCUREMENT (NPP) CCIW Transformer Recapitalization Burlington, ON

DESCRIPTION OF PROJECT

Public Works and Government Services Canada (PWGSC), Real Property Branch requires a qualified general contractor to carry out CCIW TRANSFORMER RECAPILIZATION AND RELATED WORKS at Burlington, Ontario

This work shall be in accordance with the Specifications for Project No. KW405-180719/001/PWL CCIW Transformer Recapitalization dated 2021-07-14 and their respective Drawings.

The work includes but is not limited to: general construction and modification to the existing site to allow for replacement of three transformers, located at Canada Centre of Inland Water at Burlington, ON. Including all require services and verifications like phase rotation, orientation etc. to be completed with the existing electrical system in order to successfully replace and operate the new transformers

OPTIONAL SITE VISIT

There will be a site visit on August 12, 2021 at 10:00am.

Interested bidders are to meet at 867 Lakeshore Road, Burlington, ON, L7S 1A1. Bidders must register with the Contracting Officer Isaac Kwan by email at Isaac.kwan@pwgsc.gc.ca.

Safety Attire: In order to be guaranteed access to the site visit all persons should have the proper personal

protection equipment (safety glasses, footwear, vests and hard hats etc.). Contractor`s personnel/individuals who do not have the proper safety attire may be denied access to the site.

COVID-19 Protocols for Site Visit: a. Only two bidders from each company permitted b. Wear a Non-medical masks/face covering at all times while outside of vehicle. c. Maintain 2m social distancing at all time. d. Observe proper hand hygiene while on site. Sanitize hands before entering the building and after exiting. Attendees should bring their own hand sanitizer. e. Attendance will be taken by Bidders announcing their name and Departmental Representative recording (no list passed around). f. Bidder self-screening and declaration that not ill is required at arrival (see attachment). g. Avoid social greetings (e.g. shaking hands).

COMPLETION DATE

The Contractor shall perform and complete the Work within Thirty (30) weeks from the date of notification of acceptance of the offer.

ENQUIRIES All enquiries of a technical and contractual nature, are to be submitted to the Contracting Officer, Isaac Kwan e-mail address: isaac.kwan@pwgsc.gc.ca Any clarifications or changes to the bid solicitation resulting from the site visit will be included as an amendment to the bid solicitation.

Delivery Date: 05/08/2021

The Crown retains the right to negotiate with suppliers on any procurement.

Documents may be submitted in either official language of Canada.